Salesforce Consultancy and Implementation

To provide implementation service and consultancy service for customer using Salesforce CRM
  • Delivery Method: Service
  • $ 1000.00 USD
One-time purchase,valid for 1Month(s)
Product Details

Product Highlights
- Professional Discovery to identify customers' CRM needs - Design of Salesforce environment - Implementation of Salesforce environment - Nursing Period Support (adoption planning, training, data migration)
Product Description

- Professional Discovery to identify customers' CRM needs
- Design of Salesforce environment
- Implementation of Salesforce environment
- Nursing Period Support (adoption planning, training, data migration)

Product Certifications
Product Userguide

click here to read detailed user guide.

Sales area

Available for sale in all countries

Delivery Info

  • Delivery Procedure
    Basic Delivery Process
  • Delivery Method
    Offline
  • Delivery Period
    120 Calendar Day
  • Product Warranty
    No
  • Warranty Period
  • Delivery Country/Region
    China, Hong Kong(China), Macao(China), South Korea, Taiwan(China), Indonesia, Malaysia, Myanmar, Philippines, Singapore, Thailand, Vietnam
Support

  • Support Service
    Account Success Service one year after deployment admin@brightsystem.com.hk 35211768
  • Refund Policy
    No Refund Policy
End User License Agreement

  • End User License Agreement

    The Buyer wishes to be provided with the Services (defined below) by the Service Provider and the Service Provider agrees to provide the Services to the Buyer on the terms and conditions of this Agreement.

    1. Key Terms

    1.1  Services

    The Service Provider shall provide the following services ("Services") to the Buyer in accordance with the terms and conditions of this Agreement:

          1. Name of Project: TBC
          2. Details of the Project: The service provided shall be detailed in Clause 4 of this document.

    1.2  Delivery of the Services

          1. Start date: The Service Provider shall commence the provision of the Services on [Project Start Date], provided that the initial payment is made payable from the Buyer to the Service Provider within seven working days of signing this agreement.
          2. Date of the User Acceptance Test (UAT): The Service Provider shall provide a prototype of the project to the Buyer for testing by the date of the User Acceptance Test. However, this date is subjected to delays caused by changes or suggestions made from the Buyer to the Service Provider, to which the Service Provider will not be liable. The Service Provider will not be liable for damages if there are delays caused by late or failure of earlier payments from the Buyer to the Service Provider.
          3. Product launch date: After the date of UAT, the Service Provider shall launch the product/project for usage, as long as all payments have been finalized between the parties. The Service Provider will not be liable for damages if there are delays caused by late or failure of earlier payments from the Buyer to the Service Provider.

    1.3  Price

          1. As consideration for the provision of the Services by the Service Provider, the price for the provision of the Services is HKD [Price] ("Price").
          2. The Buyer shall pay for the Service Provider’s out-of-pocket expenses, provided that both parties agree on the details.

    1.4  Nursing Period

          1. The buyer will be entitled to have [xx] days of nursing period on the project counting from the project launch date.
          2. Service delivered by Service Provider during nursing period: a) Dedicated account manager support b) Adjusting fields, page layouts and reports c) Unlimited hotline support by phone, email and WhatsApp.

     

    1.5  Payment

        1. 1. The Service Provider shall invoice the Buyer at each of the stages.
        2. 2. The Buyer shall pay such invoices within 7 days of their receipt from the Service Provider. Interest will be charged on any outstanding amount at the HK dollar prime-lending rate of HSBC.
        3. 3. All of the payments made are non-refundable.
        4. 4. Any charges payable under this Agreement are exclusive of any applicable taxes, tariff surcharges or other like amounts assessed by any governmental entity arising as a result of the provision of the Services by the Service Provider to the Buyer under this Agreement and such shall be payable by the Buyer to the Service Provider in addition to all other charges payable hereunder.
    1. General terms

    2.2  Limitation of liability

          1. Subject to the Buyers obligation to pay the Price to the Service Provider, either partys liability in contract, tort or otherwise (including negligence) arising directly out of or in connection with this Agreement or the performance or observance of its obligations under this Agreement and every applicable part of it shall be limited in aggregate to the Price.
          2. To the extent it is lawful to exclude the following heads of loss and subject to the Buyers obligation to pay the Price, in no event shall either party be liable for any loss of profits, goodwill, loss of business, loss of data or any other indirect or consequential loss or damage whatsoever.

    2.3  Term and Termination

          1. This Agreement shall be effective on the date hereof and shall continue, unless terminated sooner in accordance with Clause 2.3.2, 2.3.3 and 2.3.4 until the Completion Date.
          2. The Service Provider may terminate this Agreement upon notice in writing if the Buyer is in breach of any material obligation in this Agreement, which is not remedied (if the same is capable of being remedied) within 7 days of written notice from the other Party so to do. Upon such termination, the Buyer must pay the remainder of the Price to the Service Provider within a reasonable of time.
          3. The Service Provider may also terminate this Agreement upon notice if:
            1. a bankruptcy or an administration order is made or a receiver or administrative receiver is appointed over any of the Buyers assets or an undertaking or a resolution or petition to wind up the Buyer is passed or presented or any analogous procedure in the country of incorporation of the Service Provider or if any circumstances arise which entitle the Court or a creditor to appoint a receiver, administrative receiver or administrator or to present a winding-up petition or make a winding-up order in respect of the Buyer.
          4. The Buyer may terminate this Agreement upon notice in writing if the Service Provider is in serious breach of any material obligation in this Agreement, which is not remedied. Upon such termination, the Buyer is not liable to pay the remainder of the Price to the Service Provider.
          5. Either Party may terminate this Agreement upon notice in writing if a voluntary arrangement is approved.
          6. Any termination of this Agreement (howsoever occasioned) shall not affect any accrued rights or liabilities of The Buyer (unless specifically waived) nor shall it affect the coming into force or the continuance in force of any provision hereof which is expressly or by implication intended to come into or continue in force on or after such termination.

    2.4  Relationship of the Parties

    The Parties acknowledge and agree that the Services performed by the Service Provider, its employees, agents or sub-contractors shall be as an independent contractor and that nothing in this Agreement shall be deemed to constitute a partnership, joint venture, agency relationship or otherwise between the parties.

    2.5  Confidentiality

    Neither Party will use, copy, adapt, alter or part with possession of any information of the other which is disclosed or otherwise comes into its possession under or in relation to this Agreement and which is of a confidential nature. This obligation will not apply to information which the recipient can prove was in its possession at the date it was received or obtained or which the recipient obtains from some other person with good legal title to it or which is in or comes into the public domain otherwise than through the default or negligence of the recipient or which is independently developed by or for the recipient.

    2.6  Notices

    Any notice which may be given by a Party under this Agreement shall be deemed to have been duly delivered if delivered by hand, post, facsimile transmission or electronic mail to the address of the other Party as specified in this Agreement or any other address notified in writing to the other Party. Subject to any applicable local law provisions to the contrary, any such communication shall be deemed to have been made to the other Party, if delivered by:

          1. Post, 2 days from the date of posting;
          2. Hand or by facsimile transmission, on the date of such delivery or transmission; and
          3. Electronic mail, when the Party sending such communication receives confirmation of such delivery by electronic mail.

    2.7  Miscellaneous

          1. The failure of either party to enforce its rights under this Agreement at any time for any period shall not be construed as a waiver of such rights.
          2. If any part, term or provision of this Agreement is held to be illegal or unenforceable neither the validity or enforceability of the remainder of this Agreement shall be affected.
          3. Neither Party shall assign or transfer all or any part of its rights under this Agreement without the consent of the other Party.
          4. This Agreement may not be amended for any other reason without the prior written agreement of both Parties.
          5. This Agreement constitutes the entire understanding between the Parties relating to the subject matter hereof unless any representation or warranty made about this Agreement was made fraudulently and, save as may be expressly referred to or referenced herein, supersedes all prior representations, writings, negotiations or understandings with respect hereto.
          6. The Service Provider shall not be liable for failure to perform or delay in performing any obligation under this Agreement if the failure or delay is caused by any circumstances beyond its reasonable control, including but not limited to acts of god, war, epidemic, civil commotion or industrial dispute.
          7. The Service Provider shall not be liable for failure to perform or delay in performing any obligation under this Agreement if the failure to delay is caused by the conduct of the Buyer (which include, but not limited to, changes made to the design, changes in the details of the services, delay or failure to pay the Price when invoiced, failure to communicate with the Service Provider when required).
          8. This Clause 2.7.8 and the entire Clause 2 of this Agreement shall survive any termination or expiration.
          9. This Agreement shall be governed by the laws of the jurisdiction in which the Service Provider is located (or if the Buyer is based in more than one country, the country in which its headquarters are located) (the "Territory") and the parties agree to submit disputes arising out of or in connection with this Agreement to the non-exclusive of the courts in the Territory.
Reviews & Ratings 0

emptyImg
No Record
Total: 0
Additional Information

Delivery Method: Service

Last Updated: 2025/01/20

Category: Business Software

Vendor: 

Email: stephen.wan@brightsystem.com.hk

phone Contact Us

Chat now with Alibaba Cloud Customer Service to assist you in finding the right products and services to meet your needs.

alicare alicarealicarealicare